The House Contractor Agreement is a vital legal document used in Indonesia when engaging a contractor for residential construction projects. It serves as the primary contract between property owners and construction contractors, establishing their rights, obligations, and responsibilities throughout the construction process. This agreement is structured to comply with Indonesian construction laws, particularly Law No. 2 of 2017 on Construction Services and relevant regional regulations. The document typically includes detailed specifications for construction work, payment schedules, quality standards, timeline commitments, and dispute reֱ procedures. It's essential for protecting both parties' interests and ensuring clear communication throughout the project lifecycle, while addressing specific requirements of Indonesian construction regulations and local building codes.
Create a bespoke document in minutes, or upload and review your own.
Thank you! Your submission has been received!
Oops! Something went wrong while submitting the form.
Get your first 2 documents free
Your data doesn't train Genie's AI
You keep IP ownership of your information
Key Requirements PROMPT example:
House Contractor Agreement
"I need a House Contractor Agreement for constructing a luxury 3-story residence in Jakarta, Indonesia, with completion scheduled for December 2025, including provisions for high-end materials and custom architectural features."
Your data doesn't train Genie's AI
You keep IP ownership of your information
Thank you! Your submission has been received!
Oops! Something went wrong while submitting the form.
OR
1. Parties: Identification of the homeowner and contractor, including complete legal names, addresses, and registration details
2. Background: Context of the agreement, including property details and general purpose of the construction project
3. Definitions: Definitions of key terms used throughout the agreement
4. Scope of Work: Detailed description of the construction work to be performed, including general specifications and standards
5. Contract Price and Payment Terms: Total contract value, payment schedule, and payment conditions
6. Timeline and Completion: Project schedule, completion dates, and milestones
7. Contractor's Obligations: Key responsibilities of the contractor, including quality standards, supervision, and compliance requirements
8. Owner's Obligations: Responsibilities of the homeowner, including site access, approvals, and information provision
9. Materials and Equipment: Specifications for materials, procurement responsibilities, and quality requirements
10. Safety and Compliance: Safety requirements, permits, and regulatory compliance obligations
11. Variations and Changes: Process for handling changes to scope, specifications, or contract price
12. Quality Control and Inspection: Quality assurance procedures, inspections, and acceptance criteria
13. Warranties and Defects: Warranty terms, defect liability period, and remediation process
14. Insurance and Indemnity: Insurance requirements and indemnification provisions
15. Termination: Grounds and process for contract termination by either party
16. Dispute Reֱ: Process for resolving disputes, including mediation and arbitration procedures
17. General Provisions: Standard legal provisions including notices, governing law, and entire agreement
1. Force Majeure: Provisions for handling unforeseen circumstances and natural disasters, recommended for longer-term projects
2. Intellectual Property: Protection of designs and technical drawings, needed when custom architectural designs are involved
3. Environmental Protection: Specific environmental requirements and waste management, necessary for environmentally sensitive areas
4. Subcontracting: Terms for engaging and managing subcontractors, needed when subcontracting is permitted
5. Site Security: Security requirements for the construction site, important for high-value projects or sensitive locations
6. Temporary Facilities: Provisions for temporary structures and facilities, needed for larger construction projects
7. Financing Arrangements: Terms related to external financing or staged funding, needed when bank financing is involved
1. Schedule 1 - Detailed Scope of Work: Comprehensive technical specifications and construction drawings
2. Schedule 2 - Bill of Quantities: Detailed breakdown of quantities and prices for materials and labor
3. Schedule 3 - Payment Schedule: Detailed payment milestones and amounts
4. Schedule 4 - Construction Timeline: Detailed project schedule with milestones and critical paths
5. Schedule 5 - Material Specifications: Detailed specifications for all materials to be used
6. Schedule 6 - Quality Standards: Specific quality standards and testing requirements
7. Schedule 7 - Required Permits and Approvals: List of required permits and responsible parties
8. Appendix A - Site Plan and Drawings: Architectural and engineering drawings
9. Appendix B - Insurance Requirements: Detailed insurance specifications and coverage requirements
10. Appendix C - Safety Procedures: Detailed safety protocols and emergency procedures
Authors
Relevant legal definitions
Clauses
Relevant Industries
Construction
Real Estate
Architecture
Engineering
Building Materials
Property Development
Interior Design
Project Management
Legal Services
Insurance
Relevant Teams
Legal
Operations
Construction
Project Management
Procurement
Risk & Compliance
Property Management
Quality Assurance
Health & Safety
Contract Administration
Real Estate Development
Relevant Roles
Construction Manager
Project Director
Contract Administrator
Legal Counsel
Property Developer
Site Supervisor
Quantity Surveyor
Architect
Civil Engineer
Procurement Manager
Risk Manager
Compliance Officer
Property Manager
Construction Estimator
Quality Control Inspector
Safety Officer
Find the exact document you need
House Contractor Agreement
An Indonesian law-governed agreement between property owner and contractor for residential construction projects, outlining construction terms, payments, and responsibilities.
find out more
Builder And Owner Agreement
A Saudi Arabian law-governed agreement between property owners and builders defining construction project terms, conditions, and obligations.
find out more
Service Level Agreement (Construction)
Construction Service Level Agreement template for Philippine jurisdiction, defining performance metrics and quality standards for construction projects.
find out more
Professional Services Agreement (Construction)
A Philippine law-governed agreement for professional services in construction projects, defining service scope, terms, and regulatory compliance requirements.
find out more
Preconstruction Agreement
A Philippine law-governed agreement defining terms and conditions for preconstruction services, including design review, cost estimation, and project planning activities.
find out more
General Contractor Building Contract
A South African law-governed contract between an employer and general contractor establishing terms and conditions for construction project execution.
find out more
Construction Management Agency Contract
A South African construction contract establishing an agency relationship between a Principal and Construction Manager for professional project management services.
find out more
Sub Contracting Agreement
A Maltese law-governed agreement between a main contractor and subcontractor defining delegated work scope, terms, and obligations.
find out more
Civil Contractor Agreement
A Maltese law-governed agreement establishing the terms and conditions between a company and an independent contractor, ensuring regulatory compliance and clear business relationship parameters.
find out more
Construction Management Services Contract
A Pakistani law-governed agreement establishing terms and conditions for professional construction management services, including scope, responsibilities, and compliance requirements.
find out more
Contractor Subcontractor Contract Agreement
Austrian law-governed agreement between a main contractor and subcontractor for the provision of specified works or services, compliant with Austrian legal requirements.
find out more
ұԾ’s Security Promise
Genie is the safest place to draft. Here’s how we prioritise your privacy and security.
Your documents are private:
We do not train on your data; ұԾ’s AI improves independently
All data stored on Genie is private to your organisation
Your documents are protected:
Your documents are protected by ultra-secure 256-bit encryption
Our bank-grade security infrastructure undergoes regular external audits
We are ISO27001 certified, so your data is secure
Organizational security
You retain IP ownership of your documents
You have full control over your data and who gets to see it
Innovation in privacy:
Genie partnered with the Computational Privacy Department at Imperial College London
Together, we ran a £1 million research project on privacy and anonymity in legal contracts
Want to know more?
Visit our for more details and real-time security updates.
Read our Privacy Policy.