The General Contractor Agreement With Owner serves as the primary contract document for construction projects in Denmark, establishing the legal and operational framework between property owners/developers and general contractors. This agreement type is essential for projects where a single contractor takes primary responsibility for construction delivery, typically used in commercial, residential, and industrial developments. The document incorporates Danish construction law requirements and AB 18 standards, covering crucial aspects such as scope definition, payment structures, timeline management, quality control, and risk allocation. It's particularly important for projects requiring comprehensive contractor coordination, structured payment mechanisms, and clear delineation of responsibilities. The agreement ensures compliance with Danish regulatory requirements while providing flexibility to accommodate project-specific needs through its schedules and appendices.
Create a bespoke document in minutes, or upload and review your own.
Thank you! Your submission has been received!
Oops! Something went wrong while submitting the form.
Get your first 2 documents free
Your data doesn't train Genie's AI
You keep IP ownership聽of your information
Key Requirements PROMPT example:
General Contractor Agreement With Owner
I need a General Contractor Agreement With Owner for a commercial office building project in Copenhagen, with completion scheduled for July 2025, incorporating DGNB sustainability certification requirements and BIM implementation provisions.
1. Parties: Identification of the Owner and General Contractor, including full legal names, registration numbers, and addresses
2. Background: Context of the agreement, brief description of the project, and the basis for entering into the contract
3. Definitions: Key terms used throughout the agreement, ensuring consistent interpretation
4. Scope of Work: Detailed description of the construction work to be performed, including general obligations of the contractor
5. Contract Documents: Hierarchy and list of documents forming part of the contract, including drawings, specifications, and AB 18
6. Time for Completion: Project schedule, completion date, milestones, and provisions for extensions of time
7. Contract Sum and Payment: Price, payment schedule, variation procedures, and handling of cost adjustments
8. Contractor's Obligations: Detailed responsibilities including quality standards, supervision, and coordination with subcontractors
9. Owner's Obligations: Access to site, permits, approvals, and other owner responsibilities
10. Quality Assurance: Quality control procedures, inspections, and acceptance criteria
11. Changes and Variations: Process for handling change orders and variations to the scope of work
12. Defects and Warranties: Warranty periods, defects liability, and remediation procedures
13. Insurance and Liability: Required insurance coverage and allocation of risks between parties
14. Termination: Grounds and procedures for contract termination by either party
15. Dispute Re红杏直播: Procedures for handling disputes, including mediation and arbitration provisions
16. Governing Law: Confirmation of Danish law as governing law and jurisdiction
1. Environmental Requirements: Specific environmental obligations and sustainability requirements, included when project has particular environmental focus
2. Safety Management: Detailed safety procedures and requirements, included for complex projects or those with special safety concerns
3. Liquidated Damages: Specific provisions for damages in case of delay or other breaches, included when parties agree on predetermined compensation
4. Performance Security: Requirements for performance bonds or guarantees, included when additional security is required
5. Building Information Modeling (BIM): Specific provisions for BIM implementation and management, included for projects using BIM
6. Intellectual Property Rights: Provisions regarding ownership and use of designs and documentation, included when significant IP is involved
7. Force Majeure: Detailed provisions for handling unforeseen events, included when standard AB 18 provisions need modification
8. Confidentiality: Specific confidentiality obligations, included for sensitive projects
1. Schedule 1: Technical Specifications: Detailed technical requirements and specifications for the construction work
2. Schedule 2: Drawings and Plans: Complete set of construction drawings and plans
3. Schedule 3: Bill of Quantities: Detailed breakdown of quantities and prices for the work
4. Schedule 4: Project Timeline: Detailed project schedule including milestones and critical path
5. Schedule 5: Quality Control Plan: Specific quality control procedures and requirements
6. Schedule 6: Health and Safety Plan: Detailed safety procedures and requirements
7. Schedule 7: List of Key Personnel: Names and roles of key personnel from both parties
8. Schedule 8: Form of Payment Certificate: Template for payment applications and certificates
9. Schedule 9: Forms of Bonds and Guarantees: Templates for required bonds and guarantees
10. Schedule 10: Insurance Requirements: Detailed insurance requirements and coverage limits
Authors
Relevant legal definitions
Clauses
Relevant Industries
Commercial Construction
Residential Development
Industrial Construction
Infrastructure Development
Real Estate Development
Public Works
Healthcare Construction
Educational Facilities
Retail Construction
Hospitality Construction
Relevant Teams
Legal
Construction
Project Management
Commercial
Procurement
Risk Management
Quality Assurance
Operations
Technical Services
Contract Administration
Development
Finance
Relevant Roles
Construction Project Manager
Contract Manager
Legal Counsel
Development Director
Construction Director
Chief Operating Officer
Procurement Manager
Risk Manager
Commercial Director
Technical Director
Site Manager
Project Engineer
Quality Assurance Manager
Construction Supervisor
Cost Controller
Property Developer
Facilities Manager
Building Services Manager
Find the exact document you need
Contractor Homeowner Agreement
Danish law-governed agreement between contractor and homeowner for residential construction or renovation work.
find out more
Construction Cost Plus Contract
Danish law-governed construction agreement establishing a cost-plus pricing structure between owner and contractor, with reimbursement for approved costs plus agreed fee.
find out more
Standard Contractor Contract
A Danish law-governed contract template establishing terms and conditions between a company and independent contractor.
find out more
Agreement For Construction Work
Danish law construction agreement defining the terms and conditions between client and contractor for building works, aligned with AB 18 requirements.
find out more
Residential Contractor Contract
Danish law-compliant contract between a contractor and residential client for home construction or renovation works, incorporating consumer protection and construction regulations.
find out more
Building Work Agreement
A Danish law-governed agreement between a building contractor and property owner that establishes terms and conditions for construction works, incorporating Danish construction regulations and industry standards.
find out more
Construction Subcontract
Danish law-governed agreement between main contractor and subcontractor for construction works, aligned with AB 18 standards.
find out more
General Contractor Agreement With Owner
Danish law construction agreement between owner and general contractor, incorporating AB 18 standards and defining project execution terms.
find out more
Contract Agreement For Construction Work
Danish law-governed construction agreement establishing terms between employer and contractor, following AB 18 framework and Danish Construction Act requirements.
find out more
Simple Construction Contract
Danish law construction contract template establishing key terms between employer and contractor, aligned with Danish Construction Act and AB 18 principles.
find out more
Standard Construction Contract
Danish law construction contract based on AB 18 framework, governing the relationship between employer and contractor for building works.
find out more
骋别苍颈别鈥檚 Security Promise
Genie is the safest place to draft. Here鈥檚 how we prioritise your privacy and security.
Your documents are private:
We do not train on your data; 骋别苍颈别鈥檚 AI improves independently
All data stored on Genie is private to your organisation
Your documents are protected:
Your documents are protected by ultra-secure 256-bit encryption
Our bank-grade security infrastructure undergoes regular external audits
We are ISO27001 certified, so your data is secure
Organizational security
You retain IP ownership of your documents
You have full control over your data and who gets to see it
Innovation in privacy:
Genie partnered with the Computational Privacy Department at Imperial College London
Together, we ran a 拢1 million research project on privacy and anonymity in legal contracts
Want to know more?
Visit our for more details and real-time security updates.
Read our Privacy Policy.